Represented the general contractor on a new $70 million hospital wing for the Department of Veterans Affairs in Ann Arbor, Michigan. Following a trial on the contractor’s claims to the VA Board of Contract Appeals, the contractor was awarded time extensions for the entire period of delay (260 days) and additional compensation for extended overhead and the resulting inefficiencies. Following an appeal to the Federal Circuit, the parties settled the claims for approximately $3.1 million.

P.J. Dick, Inc., VABCA Nos. 5597, et al., 2001-2 BCA 31,647; affirmed in part, reversed in part, 324 F.3d 1364 (Fed. Cir. 2003).

Experience Center

Match our Experience to Your Needs

Experience Highlights

Class action defense on behalf of staffing agency and transaction technology provider
Represented clients, including temporary staffing agencies and a worldwide provider of consumer transaction technologies, in the defense of multiple more
Transactions for brokerage firms
Represented one of the leading U.S.-based brokerage firms in commercial loan transactions for its brokerage customers; loans secured by real and more
Public offering of common stock by Northfield Bancorp, Incorporated
Represented the underwriter, Sandler O' Neill & Partners, L.P., in a $355.6 million public offering of common stock by Northfield Bancorp, Inc. more
Insurance coverage for mold contamination at a hotel
The firm served as lead counsel in litigation seeking coverage under an all risk property policy for the cost of remediating and repairing mold more